Terms & Conditions:   THE BOEING COMPANY GENERAL PROVISIONS (Fixed Price Service Contract) GP 2 (Rev02/01/2001) 1. FORMATION OF CONTRACT. This proposed contract is Buyer's offer to purchase the goods and services ("Services") described in this offer. Acceptance is strictly limited to the terms and conditions included in this offer. Unless specifically agreed to in writing by Buyer's Authorized Procurement Representative, Buyer objects to, and is not bound by, any term or condition that differs from or adds to this offer. Seller's commencement of performance or acceptance of this offer in any manner shall conclusively evidence acceptance of this offer as written. 2. SCOPE OF SERVICES. During the term of this contract, Seller shall furnish the Services set forth in the contract. 3. INDEPENDENT CONTRACTOR. Seller is an independent contractor for all purposes. Seller shall have complete control over the performance of, and the details for accomplishing, the Services. In no event shall Seller or its agents, representatives or employees be deemed to be agents, representatives or employees of Buyer. Seller's employees shall be paid exclusively by Seller for all services performed. Seller shall comply with all requirements and obligations relating to such employees under federal, state and local law (or foreign law, if applicable). Such compliance shall include, but not be limited to, laws regarding minimum wages, social security, unemployment insurance, federal and state income taxes and workers' compensation insurance. 4. STANDARDS. Seller shall assign personnel satisfactory to Buyer. At any time and for any reason, Buyer may require Seller to withdraw the services of any person and require that Seller promptly provide replacements for such persons satisfactory to Buyer. In addition to the other indemnification provisions within this contract, Seller specifically agrees to indemnify and hold harmless Buyer from and against any liabilities, claims, charges or suits for alleged losses, costs, damages or expenses arising from Buyer's exercise of its rights hereunder. 5. WARRANTY. Seller warrants that all Services performed hereunder shall be performed by employees or agents of Seller who are experienced and skilled in their profession and in accordance with industry standards. Seller further warrants that all Services performed under this contract, at the time of acceptance, shall be free from defects in workmanship and conform to the requirements of this contract. Buyer shall give written notice of any defect or nonconformance to Seller within one year from the date of acceptance by Buyer. Buyer may, at its option, either (a) require correction or reperformance of any defective or nonconforming services, or (b) make an equitable adjustment in the price of this contract. If Seller is required to correct or reperform the Services, such correction or reperformance shall be at Seller's expense. Any Services corrected or reperformed shall be subject to this article to the same extent as Services initially performed. If Seller fails or refuses to correct or reperform, Buyer may correct or replace with similar services and charge Seller for any cost to Buyer or make an equitable adjustment in the price of this contract. 6. TAXES. Unless this contract specifies otherwise, the price of this contract includes, and Seller is liable for and shall pay, all taxes, impositions, charges and exactions imposed on or measured by this contract except for applicable sales and use taxes that are separately stated on Seller's invoice. Prices shall not include any taxes, impositions, charges or exactions for which Buyer has furnished a valid exemption certificate or other evidence of exemption. 7. INVOICE AND PAYMENT. As compensation for services to be performed by Seller, Buyer shall pay Seller as set forth in this contract. Buyer shall have no liability for any other expenses or costs incurred by Seller. Payment due date, including discount periods, shall be computed from the date of the later of the scheduled delivery date, the actual delivery date or the date of receipt of a correct invoice. Payment shall be deemed to have been made on the date the Buyer's check is mailed or payment is otherwise tendered. Seller shall promptly repay to Buyer any amounts paid in excess of amounts due Seller. 8. CHANGES a. Buyer's Authorized Procurement Representative may, without notice to sureties and in writing, direct changes within the general scope of this contract in any of the following: (i) technical requirements and descriptions, specifications, statement of work, drawings or designs; (ii) shipment or packing methods; (iii) place of delivery, inspection or acceptance; (iv) reasonable adjustments in quantities or delivery schedules or both; (v) amount of Buyer-furnished property; and, if this contract includes services, (vi) description of services to be performed; (vii) the time of performance (e.g., hours of the day, days of the week, etc.); and (viii) place of performance. Seller shall comply immediately with such direction. b. If such change increases or decreases the cost or time required to perform this contract, Buyer and Seller shall negotiate an equitable adjustment in the price or schedule, or both, to reflect the increase or decrease. Buyer shall modify this contract in writing accordingly. Unless otherwise agreed in writing, Seller must assert any claim for adjustment to Buyer's Authorized Procurement Representative in writing within 25 days and deliver a fully supported proposal to Buyer's Authorized Procurement Representative within 60 days after Seller's receipt of such direction. Buyer may, at its sole discretion, consider any claim regardless of when asserted. If Seller's proposal includes the cost of property made obsolete or excess by the change, Buyer may direct the disposition of the property. Buyer may examine Seller's pertinent books and records to verify the amount of Seller's claim. Failure of the parties to agree upon any adjustment shall not excuse Seller from performing in accordance with Buyer's direction. c. If Seller considers that Buyer's conduct constitutes a change, Seller shall notify Buyer's Authorized Procurement Representative immediately in writing as to the nature of such conduct and its effect upon Seller's performance. Pending direction from Buyer's Authorized Procurement Representative, Seller shall take no action to implement any such change. 9. DISPUTES. Any dispute that arises under or is related to this contract that cannot be settled by mutual agreement of the parties may be decided by a court of competent jurisdiction. Pending final resolution of any dispute, Seller shall proceed with performance of this contract according to Buyer's instructions so long as Buyer continues to pay amounts not in dispute. 10. FORCE MAJEURE. Seller shall not be liable for the excess reprocurement costs pursuant to the "Cancellation for Default" article of this contract incurred by Buyer because of any failure to perform this contract under its terms if the failure arises from causes beyond the control and without the fault or negligence of Seller. Examples of these causes are (a) acts of God or of the public enemy, (b) acts of the Government in either its sovereign or contractual capacity, (c) fires, (d) floods, (e) epidemics, (f) quarantine restrictions, (g) strikes, (h) freight embargoes and (i) unusually severe weather. In each instance, the failure to perform must be beyond the control and without the fault or negligence of Seller. If the delay is caused by a delay of a subcontractor of Seller and if such delay arises out of causes beyond the reasonable control of both, and without the fault or negligence of either, Seller shall not be liable for excess costs unless the goods or services to be furnished by the subcontractor were obtainable from other sources in sufficient time to permit Seller to meet the required delivery schedules. Seller shall notify Buyer in writing within 10 days after the beginning of any such cause. 11. TERMINATION FOR CONVENIENCE. Buyer reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, Seller shall immediately cease all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. In case of termination for convenience by Buyer of all or any part of this contract, Seller may submit a claim to Buyer within 60 days after the effective date of termination. In no event shall Buyer be obligated to pay Seller any amount in excess of the contract price. The provisions of this article shall not limit or affect the right of Buyer to cancel this contract for default. 12. CANCELLATION FOR DEFAULT a. Buyer may, by written notice to Seller, cancel all or part of this contract (i) if Seller fails to deliver the Services within the time specified by this contract or any written extension; (ii) if Seller fails to perform any other provision of this contract or fails to make progress, so as to endanger performance of this contract, and, in either of these two circumstances, does not cure the failure within 10 days after receipt of notice from Buyer specifying the failure; or (iii) in the event of Seller's bankruptcy, suspension of business, insolvency, appointment of a receiver for Seller's property or business, or any assignment, reorganization or arrangement by Seller for the benefit of its creditors. b. Seller shall continue work not canceled. 13. ASSIGNMENT, DELEGATION AND SUBCONTRACTING. Seller shall not assign any of its rights or interest in this contract or subcontract all or substantially all of its performance of this contract without Buyer's prior written consent. Seller shall not delegate any of its duties or obligations under this contract. Seller may assign its right to monies due or to become due. No assignment, delegation or subcontracting by Seller, with or without Buyer's consent, shall relieve Seller of any of its obligations under this contract or prejudice any of Buyer's rights against Seller whether arising before or after the date of any assignment. This article does not limit Seller's ability to purchase standard commercial supplies or raw materials. 14. INDEMNIFICATION, INSURANCE AND PROTECTION OF PROPERTY a. Indemnification Negligence of Seller or Subcontractor. Seller shall indemnify and hold harmless The Boeing Company, its subsidiaries, and their directors, officers, employees and agents from and against all actions, causes of action, liabilities, claims, suits, judgments, liens, awards and damages of any kind and nature whatsoever for property damage, personal injury or death (including without limitation injury to or death of employees of Seller or any subcontractor thereof) and expenses, costs of litigation and counsel fees related thereto or incident to establishing the right to indemnification, arising out of or in any way related to this contract, the performance thereof by Seller or any subcontractor thereof or other third parties, including, without limitation, the provision of services, personnel, facilities, equipment, support, supervision or review. The foregoing indemnity shall apply only to the extent of the negligence of Seller, any subcontractor thereof or their respective employees. In no event shall Seller's obligations hereunder be limited to the extent of any insurance available to or provided by Seller or any subcontractor thereof. Seller expressly waives any immunity under industrial insurance, whether arising out of statute or source, to the extent of the indemnity set forth in this paragraph (a). b. Commercial General Liability. If Seller or any subcontractor thereof will be performing work on Buyer's premises, Seller shall carry and maintain, and ensure that all subcontractors thereof carry and maintain, throughout the period when work is performed and until final acceptance by Buyer, Commercial General Liability insurance with available limits of not less than one million dollars ($l,000,000) per occurrence for bodily injury and property damage combined. Such insurance shall contain coverage for all premises and operations, broad form property damage, contractual liability (including, without limitation, that specifically assumed under paragraph (a) herein) and goods and completed-operations insurance with limits of not less than one million dollars ($1,000,000) per occurrence for a minimum of 24 months after final acceptance of the work by Buyer. Such insurance shall not be maintained on a per-project basis unless the respective Seller or subcontractor thereof does not have blanket coverage. c. Automobile Liability. If licensed vehicles will be used in connection with the performance of the work, Seller shall carry and maintain, and ensure that any subcontractor thereof who uses a licensed vehicle in connection with the performance of the work carries and maintains, throughout the period when work is performed and until final acceptance by Buyer, Business Automobile Liability insurance covering all vehicles, whether owned, hired, rented, borrowed or otherwise, with available limits of not less than one million dollars ($1,000,000) per occurrence combined single limit for bodily injury and property damage. d. Workers' Compensation. Throughout the period when work is performed and until final acceptance by Buyer, Seller shall, and ensure that any subcontractor thereof shall, cover or maintain insurance in accordance with the applicable laws relating to Workers' Compensation with respect to all of their respective employees working on or about Buyer's premises. If Buyer is required by any applicable law to pay any Workers' Compensation premiums with respect to an employee of Seller or any subcontractor, Seller shall reimburse Buyer for such payment. e. Certificates of Insurance. Prior to commencement of the work, Seller shall provide for Buyer's review and approval certificates of insurance reflecting full compliance with the requirements set forth in paragraphs (b) Commercial General Liability, (c) Automobile Liability and (d) Workers' Compensation. Such certificates shall be kept current and in compliance throughout the period when work is being performed and until final acceptance by Buyer, and shall provide for 30 days advance written notice to Buyer in the event of cancellation. Failure of Seller or any subcontractor thereof to furnish certificates of insurance, or to procure and maintain the insurance required herein or failure of Buyer to request such certificates, endorsements or other proof of coverage shall not constitute a waiver of Seller's or subcontractor's obligations hereunder. f. Self-Assumption. Any self-insured retention, deductibles and exclusions in coverage in the policies required under this article shall be assumed by, for the account of and at the sole risk of Seller or the subcontractor which provides the insurance and to the extent applicable shall be paid by such Seller or subcontractor. In no event shall the liability of Seller or any subcontractor thereof be limited to the extent of any of the minimum limits of insurance required herein. g. Protection of Property. Seller assumes, and shall ensure that all subcontractors thereof and their respective employees assume, the risk of loss or destruction of or damage to any property of such parties whether owned, hired, rented, borrowed or otherwise. Seller waives, and shall ensure that any subcontractor thereof and their respective employees waive, all rights of recovery against Buyer, its subsidiaries and their respective directors, officers, employees and agents for any such loss or destruction of or damage to any property of Seller, any subcontractor or their respective employees. h. At all times Seller shall, and ensure that any subcontractor thereof shall, use suitable precautions to prevent damage to Buyer's property. If any such property is damaged by the fault or negligence of Seller or any subcontractor thereof, Seller shall, at no cost to Buyer, promptly and equitably reimburse Buyer for such damage or repair or otherwise make good such property to Buyer's satisfaction. If Seller fails to do so, Buyer may do so and recover from Seller the cost thereof. 15. BUYER'S PROPERTY. Seller shall clearly mark, maintain an inventory of and keep segregated or identifiable all of Buyer's property and all property to which Buyer acquires an interest by virtue of this contract. Seller assumes all risk of loss, destruction or damage of such property while in Seller's possession, custody or control. Upon request, Seller shall provide Buyer with adequate proof of insurance against such risk of loss. Seller shall not use such property other than in performance of this contract without Buyer's prior written consent. Seller shall notify Buyer's Authorized Procurement Representative if Buyer's property is lost, damaged or destroyed. As directed by Buyer, upon completion, termination or cancellation of this contract, Seller shall deliver such property, to the extent not incorporated in delivered materials, to Buyer in good condition subject to ordinary wear and tear and normal manufacturing losses. Nothing in this article limits Seller's use, in its direct contracts with the Government, of property in which the Government has an interest. 16. ACCESS TO PLANTS AND PROPERTIES. Seller shall comply with all the rules and regulations established by Buyer for access to and activities in and around premises controlled by Buyer or Buyer's customer. 17. NOTICE TO BUYER OF LABOR DISPUTES. Whenever Seller has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this contract, Seller shall immediately give notice thereof, including all relevant information, to Buyer. 18. PATENT, TRADEMARK AND COPYRIGHT INDEMNITY. Seller will indemnify, defend and hold harmless Buyer and its customer from all claims, suits, actions, awards (including, but not limited to, awards based on intentional infringement of patents known at the time of such infringement, exceeding actual damages and/or including attorneys' fees and/or costs), liabilities, damages, costs and attorneys' fees related to the actual or alleged infringement of any United States or foreign intellectual property right (including, but not limited to, any right in a patent, copyright, industrial design or semiconductor mask work, or based on misappropriation or wrongful use of information or documents) and arising out of the manufacture, sale or use of products by either Buyer or its customer. Buyer and/or its customer will duly notify Seller of any such claim, suit or action; and Seller will, at its own expense, fully defend such claim, suit or action on behalf of indemnitees. Seller will have no obligation under this article with regard to any infringement arising from (a) Seller's compliance with formal specifications issued by Buyer where infringement could not be avoided in complying with such specifications or (b) use or sale of products in combination with other items when such infringement would not have occurred from the use or sale of those products solely for the purpose for which they were designed or sold by Seller. For purposes of this article only, the term Buyer will include The Boeing Company and all Boeing subsidiaries and all officers, agents and employees of Boeing or any Boeing subsidiary. 19. CONFIDENTIAL, PROPRIETARY AND TRADE SECRET INFORMATION AND MATERIALS. Buyer and Seller shall each keep confidential and protect from unauthorized use and disclosure all (a) confidential, proprietary and/or trade secret information; (b) tangible items containing, conveying or embodying such information; and (c) tooling identified as being subject to this clause and obtained, directly or indirectly, from the other in connection with this contract or other agreement referencing this contract (collectively referred to as "Proprietary Information and Materials"). Buyer and Seller shall each use Proprietary Information and Materials of the other only in the performance of and for the purpose of this contract and/or any other agreement referencing this contract. However, despite any other obligations or restrictions imposed by this article, Buyer shall have the right to use, disclose and reproduce Seller's Proprietary Information and Materials, and make derivative works thereof, for the purposes of testing, certification, use, sale or support of any product delivered under this contract or any other agreement referencing this contract. Any such use, disclosure, reproduction or derivative work by Buyer shall, whenever appropriate, include a restrictive legend suitable for the particular circumstances. The restrictions on disclosure or use of Proprietary Information and Materials by Seller shall apply to all materials derived by Seller or others from Buyer's Proprietary Information and Materials. Upon Buyer's request at any time, and in any event upon the completion, termination or cancellation of this contract, Seller shall return to Buyer all of Buyer's Proprietary Information and Materials and all materials derived therefrom, unless specifically directed otherwise in writing by Buyer. Seller shall not, without the prior written authorization of Buyer, sell or otherwise dispose of (as scrap or otherwise) any parts or other materials containing, conveying, embodying or made in accordance with or by reference to any Proprietary Information and Materials of Buyer. Prior to disposing of such parts or other materials as scrap, Seller shall render them unusable. Buyer shall have the right to audit Seller's compliance with this article. Seller may disclose Proprietary Information and Materials of Buyer to its subcontractors as required for the performance of this contract, provided that each such subcontractor first agrees in writing to the same obligations imposed upon Seller under this article relating to Proprietary Information and Materials. Seller shall be liable to Buyer for any breach of such obligation by such subcontractor. The provisions of this article are effective in lieu of any restrictive legends or notices applied to Proprietary Information and Materials. The provisions of this article shall survive the performance, completion, termination or cancellation of this contract. 20. PUBLICITY. Without Buyer's prior written approval, Seller shall not, and shall require that its subcontractors at any tier shall not, release any publicity, advertisement, news release or denial or confirmation of same regarding this contract or the Services or program to which it pertains. Seller shall be liable to Buyer for any breach of such obligation by any subcontractor. 21. EVIDENCE OF CITIZENSHIP OR IMMIGRANT STATUS. Buyer may be required to obtain information concerning citizenship or immigrant status of Seller's personnel or Seller's subcontractor personnel entering the premises of Buyer. Seller agrees to furnish this information before commencement of work and at any time thereafter before substituting or adding new personnel to work on Buyer's premises. Information submitted by Seller shall be certified by an authorized representative of Seller as being true and correct. 22. GRATUITIES. Seller warrants that neither it nor any of its employees, agents or representatives have offered or given, or will offer or give, any gratuities to Buyer's employees, agents or representatives for the purpose of securing this contract or securing favorable treatment under this contract. 23. OFFSET CREDITS a. To the exclusion of all others, Buyer or its assignees shall be entitled to all industrial benefits or offset credits which might result from this contract. Seller shall provide documentation or information which Buyer or its assignees may reasonably request to substantiate claims for industrial benefits or offset credits. b. Seller agrees to use reasonable efforts to identify the foreign content of goods or services which Seller either produces itself or procures from subcontractors for work directly related to this contract. Promptly after selection of a foreign subcontractor for work under this contract, Seller shall notify Buyer of the name, address, subcontract point of contact (including telephone number) and dollar value of the subcontract. 24. UTILIZATION OF SMALL BUSINESS CONCERNS. Seller agrees to actively seek out and provide the maximum practicable opportunities for small businesses, small disadvantaged businesses, women-owned small businesses, minority business enterprises, historically black colleges and universities and minority institutions, Historically Underutilized Business Zone small business concerns and US Veteran and Service-Disabled Veteran Owned small business concerns to participate in the subcontracts Seller awards to the fullest extent consistent with the efficient performance of this contract. 25. RIGHTS AND REMEDIES. Any failures, delays or forbearances of either party in insisting upon or enforcing any provisions of this contract, or in exercising any rights or remedies under this contract, shall not be construed as a waiver or relinquishment of any such provisions, rights or remedies; rather, the same shall remain in full force and effect. Except as otherwise limited in this contract, the rights and remedies set forth herein are cumulative and in addition to any other rights or remedies that the parties may have at law or in equity. If any provision of this contract is or becomes void or unenforceable by law, the remainder shall be valid and enforceable. 26. COMPLIANCE WITH LAWS. Seller shall comply with all applicable statutes and government rules, regulations and orders, including those pertaining to United States Export Controls. 27. GOVERNING LAW. This contract shall be governed by and construed in accordance with the laws of the state of Washington. No consideration shall be given to Washington's conflict of laws rules. This contract excludes the application of the 1980 United Nations Convention on Contracts for the International Sale of Goods. 28. GOVERNMENT CLAUSES. Government clauses applicable to this contract are incorporated herein either by attachment to this document or by some other means of reference. 29. PACKING AND SHIPPING a. Seller shall pack the materials to prevent damage and deterioration. Seller shall comply with carrier tariffs. Unless this contract specifies otherwise, the price includes shipping charges for materials sold F.O.B. destination. Unless otherwise specified in this contract, materials sold F.O.B. place of shipment shall be forwarded collect. Seller shall make no declaration concerning the value of the materials shipped except on the materials where the tariff rating is dependent upon released or declared value. In such event, Seller shall release or declare such value at the maximum value within the lowest rating. Buyer may charge Seller for damage to or deterioration of any materials resulting from improper packing or packaging. b. Unless this contract specifies otherwise, Seller will ship the materials in accordance with the following instructions: (i) Shipments by Seller or its subcontractors must include packing sheets containing Buyer's contract number, line item number, description and quantity of materials shipped, part number or size, if applicable, and appropriate evidence of inspections. A shipment containing hazardous and nonhazardous materials must have separate packing sheets for the hazardous and nonhazardous materials. Seller shall not include vermiculite or other hazardous substance in any packing material included with the Goods. Items shipped on the same day will be consolidated on one bill of lading or airbill unless Buyer's Authorized Procurement Representative authorizes otherwise. The shipping documents will describe the material according to the applicable classification and/or tariff. The total number of shipping containers will be referenced on all shipping documents. Originals of all Government bills of lading will be surrendered to the origin carrier at the time of shipment. (ii) Seller will not insure any FOB origin shipment unless authorized by Buyer. (iii) Seller will label each shipping container with the contract number and the number that each container represents of the total number being shipped (e.g., box 1 of 2, box 2 of 2). (iv) Buyer will select the carrier and mode of transportation for all shipments where freight costs will be charged to Buyer. (v) Seller will include copies of documentation supporting prepaid freight charges (e.g., carrier invoices or UPS shipping log/manifest), if any, with its invoices. (vi) If Seller is unable to comply with the shipping instructions in this contract, Seller will contact Buyer's Traffic Management Department referenced elsewhere in this contract or Buyer's Authorized Procurement Representative. 30. QUALITY CONTROL. Seller shall establish and maintain a quality control system acceptable to Buyer for the Services purchased under this contract. Seller shall permit Buyer to review procedures, practices, processes and related documents to determine such acceptability. 31. RIGHTS OF BUYER'S CUSTOMERS AND REGULATORS TO PERFORM INSPECTION, SURVEILLANCE, AND TESTING. Buyer's rights to perform inspections, surveillance and tests and to review procedures, practices, processes and related documents related to quality assurance, quality control, flight safety- and configuration control shall extend to the customers of Buyer that are departments, agencies or instrumentalities of the United States Government and to the United States Government Federal Aviation Administration and any successor agency or instrumentality of the United States Government. Buyer may also, at Buyer's option, by prior written notice from Buyer's Authorized Procurement Representative, extend such rights to other customers of Buyer and to agencies or instrumentalities of foreign governments equivalent in purpose to the Federal Aviation Administration. Seller shall cooperate with any such United States Government-directed or Buyer-directed inspection, surveillance, test or review without additional charge to Buyer. Nothing in this contract shall be interpreted to limit United States Government access to Seller's facilities pursuant to law or regulation. 32. INSPECTION a. At no additional cost to Buyer, Services shall be subject to inspection, surveillance and test at reasonable times and places, including Seller's subcontractors' locations. Buyer shall perform inspections, surveillance and tests so as not to unduly delay the work. b. Seller shall maintain an inspection system acceptable to Buyer for the Services purchased under this contract. c. If Buyer performs an inspection or test on the premises of Seller or its subcontractors, Seller shall furnish, and require its subcontractors to furnish, without additional charge, reasonable facilities and assistance for the safe and convenient performance of these duties. 33. ACCEPTANCE. Buyer shall accept the Services or give Seller notice of rejection within a reasonable time after delivery, notwithstanding any payment or prior test or inspection. No inspection, test, delay or failure to inspect or test or failure to discover any defect or other nonconformance shall relieve Seller of any of its obligations under this contract or impair any rights or remedies of Buyer or Buyer's customers. 34. REJECTION a. If Seller delivers nonconforming Services, Buyer may require Seller to promptly correct or replace the nonconforming Services. Redelivery to Buyer of any corrected or replaced Services shall be at Seller's expense, limited to Seller's hourly rate as set forth in this contract, excluding that portion of the rate attributable to profit. b. In addition Buyer may (i) correct the nonconforming Services or (ii) obtain replacement Services from another source at Seller's expense. c. Seller shall not redeliver corrected or rejected Services without disclosing the former rejection or requirement for correction. Seller shall disclose any corrective action taken. All repair, replacement and other correction and redelivery shall be completed within the original delivery schedule or such later time as Buyer may reasonably direct. 35. SELLER NOTICE OF DISCREPANCIES. Seller shall immediately notify Buyer in writing when discrepancies in Seller's process or materials are discovered or suspected which may affect the Services delivered or to be delivered under this contract. 36. SCHEDULE a. Seller shall strictly adhere to the shipment or delivery schedules specified in this contract. In the event of any anticipated or actual delay, Seller shall: (i) promptly notify Buyer in writing of the reasons for the delay and the actions being taken to overcome or minimize the delay; (ii) provide Buyer with a written recovery schedule; and (iii), if requested by Buyer, ship via air or expedited routing to avoid or minimize delay to the maximum extent possible, unless Seller is excused from prompt performance as provided in the "Excusable Delays" clause. The added premium transportation costs are to be borne by Seller. b. Seller shall not deliver Services prior to the scheduled delivery dates unless authorized by Buyer. 37. SUSPENSION OF WORK a. Buyer's Authorized Procurement Representative may, by written order, suspend all or part of the work to be performed under this contract for a period not to exceed 100 days. Within such period of any suspension of work, Buyer shall (i) cancel the suspension of work order; (ii) terminate this contract in accordance with the "Termination for Convenience" article of this contract; (iii) cancel this contract in accordance with the "Cancellation for Default" article of this contract; or (iv) extend the stop work period. b. Seller shall resume work whenever a suspension is canceled. Buyer and Seller shall negotiate an equitable adjustment in the price or schedule or both if (i) this contract is not canceled or terminated; (ii) the suspension results in a change in Seller's cost of performance or ability to meet the contract delivery schedule; and (iii) Seller submits a claim for adjustment within 20 days after the suspension is canceled. 38. ENTIRE AGREEMENT. This contract contains the entire agreement of the parties and supersedes any and all prior agreements, understandings and communications between Buyer and Seller related to the subject matter of this contract. No amendment or modification of this contract shall bind either party unless it is in writing and is signed by Buyer's Authorized Procurement Representative and an authorized representative of Seller.